Legals April 7, 2018

No. 25280 INVITATION TO BID Notice is hereby given that the Board of County Commissioners of Flathead County, Montana, will receive sealed bids for: 2018 Dust Cost Share Program All sealed bids, plainly marked "SEALED BID - 2018 Dust Cost Share Program" must be in the hands of the Clerk to the Board of County Commissioners, 800 South Main, Room 302, Kalispell, MT, 59901, on or before 8:45 a.m., local time, Wednesday, April 25, 2018. Bids will be opened and read at 9:30 a.m. in the Commissioners' Chambers, located on the third floor of the County Courthouse. The project consists of placing dust suppressant throughout the Flathead County Roadway System. The Bid will consist of placing approximately 488,793.00 linear feet of magnesium chloride and watering (as required) to existing roadways, assumed at 24 feet wide. Various roadways will be receiving dust control improvements in Flathead County, and the Contractor should be prepared to mobilize equipment on a daily basis. All Bids must be in accordance with the Contract Documents on file with the Flathead County Road & Bridge Department, 1249 Willow Glen Drive, Kalispell, Montana, (406) 758-5790. Copies of the Contract Documents for use in preparing Bids may be obtained from Flathead County Road Department at the address stipulated above upon receipt of a non-refundable deposit of $50.00 for each set of documents, including drawings. A pre-bid conference will be held at the office of Flathead County Road Department, commencing at 11:00 a.m., Wednesday, April 18, 2018. Those interested in bidding the project are encouraged to attend this meeting. Bids will be received on a price basis as described in the Contract Documents. Bid security in the amount of 10 percent of the total Bid must accompany each Bid. Within 10 calendar days after the Notice of Award, the successful Bidder will be required to furnish a Performance Bond and a Labor and Materials Payment Bond guaranteeing faithful performance and the payment of all bills and obligations arising from the performance of the contract. The bonds will each be equal to 100 percent of the contract amount. Work at the site is to commence within 10 calendar days after the written Notice to Proceed is issued. Completion of the work is required within Twenty One (21) consecutive calendar days following commencement of work. The project includes liquidated damages that will be assessed as set forth in the Special Provisions per calendar day if the work is not complete within the allotted contract time. Each bidder will be required to be registered with the State of Montana's Department of Labor and Industry prior to bidding this project. Forms for registration are available from the Department of Labor and Industry, P.O. Box 8011, 1805 Prospect, Helena, Montana 59604-8011. Information on registration can be obtained by calling 1-406-444-7734. All laborers and mechanics employed by Contractor or subcontractor in performance of the construction work shall be paid prevailing wages at rates as may be required by the laws of Flathead (County) and the state of Montana. Flathead County will withhold a 1% gross receipts tax to be forwarded to the State of Montana. Bids must include a Special Fuel Users Permit Number. No Bid may be withdrawn within a period of 60 days after the date for opening bids. Flathead County reserves the right to reject all Bids, to waive informalities, and to reject nonconforming, irregular, non-responsive or conditional Bids. Flathead County is an Equal Opportunity Employer. DATED this 2nd of April, 2018. BOARD OF COUNTY COMMISSIONERS Flathead County, Montana By: /s/ Pamela J. Holmquist Pamela J. Holmquist, Chairman April 7, 14, 2018 MNAXLP ________________________

No. 25257 Michael S. Joyner MACKOFF KELLOGG LAW FIRM 38 Second Ave E Dickinson, ND 58601 (701) 227-1841 Attorney for Plaintiff mjoyner@mackoff.com MT Bar No. 49397083 MONTANA ELEVENTH JUDICIAL DISTRICT COURT, FLATHEAD COUNTY Federal National Mortgage Association, Plaintiff, vs. Dennis M. Pewitt; Dorothy E. Pewitt; Constance S. Davis, and all persons known or unknown claiming an interest to the property, Defendants. Cause: DV-18-151 SUMMONS FOR PUBLICATION ROBERT B ALLISON THE STATE OF MONTANA TO THE ABOVE NAMED DEFENDANT, ALL PERSONS KNOWN OR UNKNOWN CLAIMING AN INTEREST TO THE PROPERTY: You are hereby summoned to answer the Complaint in this action, which is filed in the office of the Clerk of this Court, a copy of which is herewith served upon you, and to file your Answer and serve a copy thereof upon the Plaintiff's attorney within twenty-one (21) days after the service of this Summons, exclusive of the day of service; and in case of your failure to appear or answer, Judgment will be taken against you by default for the relief demanded in the Complaint. This action relates to a declaratory judgment and easement action involving the following described real properties in the County of Flathead, State of Montana: 1) That portion of the NW 1/4 of the NE 1/4 in Section 27, Township 27 North, Range 22 West, P.M.M., Flathead County, Montana described as follows: Commencing at the North Quarter corner of Section 27 at a found brass cap; thence South 40°25`32" East a distance of 484.29 feet to a set 5/8" rebar on the centerline of an existing 60` road and utility easement and the True Point of Beginning; thence along said easement the following three courses: Thence at a point of curvature, along a curve to the right with a radial bearing of South 66°59`12" East, a radius of 186.59 feet through a central angle of 72°13`56", for an arc length of 235.23 feet to a set 5/8" rebar and to a point of curvature; thence on a curve to the left with a radial bearing of South 05°14`45" West, a radius of 116.11 feet; through a central angle of 70°23`17" for an arc length of 142.64 feet, to a set 5/8" rebar and a point of tangency having a radial bearing of South 65°08`33" East; thence North 24°51`27" East a distance of 61.02 feet to a set 5/8" rebar; thence leaving said easement South 64°49`00" East a distance of 466.68 feet to a set 5/8" rebar; thence South 33°52`15" West a distance of 459.09 feet to a set 5/8" rebar; thence North 55°14`52" West a distance of 604.74 feet to a set 5/8" rebar, which point is on the centerline of said easement and the Point of Beginning. Parcel A of Certificate of Survey No. 15253. TOGETHER WITH a non-exclusive easement for ingress and egress and utility purposes over and across the grantors remaining property in the NW1/4 NE1/4 as depicted on Certificate of Survey No. 15253. 2) The Northwest quarter of the Northeast quarter of Section 27, Township 27 North, Range 22 West, P.M.M., Flathead County, Montana. Excepting therefrom Parcel A of Certificate of Survey No. 15253, Records of Flathead County, Montana. 3) The East half of the Southwest quarter of the Northeast quarter of Section 27, Township 27 North, Range 22 West, P.M.M., Flathead County, Montana, described as follows: Tract 23 of Certificate of Survey No. 3346 Excepting therefrom Parcel 2 of Certificate of Survey No. 18715, Records of Flathead County, Montana. 4) A tract of land situated, lying and being in the Southwest quarter of the Northeast quarter and in the East half of the Northwest quarter of Section 27, Township 27 North, Range 22 West, P.M.M., Flathead County, Montana, and more particularly described as follows to wit: Tract 1 of Certificate of Survey No. 19222. WITNESS my hand and seal of said Court, this 14th day of February, 2018. /s/ Peg. L. Allison Clerk of the District Court Dated this 9th day of February, 2018. Michael S. Joyner MACKOFF KELLOGG LAW FIRM 38 Second Ave E Dickinson, ND 58601 (701) 227-1841 Attorney for Plaintiff mjoyner@mackoff.com MT Bar No. 49397083 By: Michael S. Joyner Michael S. Joyner, Attorney March 24, 31, and April 7, 2018 MNAXLP -----------------------------------------